10 – Recovery of all other impacted communities and infrastructure

Payment of 39 agreements in September/24 of the Axis 04 Judicial process, totaling 306 payments, which corresponds to 40% of the total scope of PG10 in this process.

CIF Resolution No. 827/24 changing the obligation to pay for the scope of road maintenance in the municipality of Barra Longa/MG, with the transfer of equipment to the City Hall.

CIF Resolution No. 828/24 changing the obligation to pay for the scope of road maintenance in the municipality of Mariana/MG, with the transfer of equipment to the City Hall.

In August 2024, a transfer of R$1,928.50 was made to the municipality of Santana do Paraíso, referring to the request for a Review of the PGIRS;

In August 2024, a transfer of R$474,880.46 was made to the municipality of Bom Jesus do Galho, referring to the request for the implementation of the sewage system in the District of Revés do Belém;

Start of construction work on the Campinas x Barretos Walkway in the municipality of Barra Longa on 07/09/2024.

- Deliberation 798, of 06/27/2024, approving the closure of items “a” and “k” of clause 84.

- Land release for the start of work on the Walkway between Campinas and Barretos.

- Deliberation 787, of 05/17/2024, approving the closure of item “s” of clause 84;
- Request from the Judicial Branch Institutions, on 05/14/2024 to the judge of the 4th Court, to extend the period of another 15 days for demonstration at the AXIS 8 hub;
- Stoppage due to demonstration by the community, of the Campo dos Rodoviários and Quadra da Volta da Capela works between 05/16/24 and 05/3/24;
- Start of works on Quadra da Volta da Capela in Barra Longa;
- Start of individual negotiations, approval and payments of Axis 04 agreements;
- Signing of the delivery term for the drainage works of the waste landfill, the clay loan area, the construction waste landfill at the Vista Alegre farm in Barra Longa.

Hearing at the 4th Federal Civil Court on 04/04/2024 on the topic of Axis 04, celebrating the agreement. Was
presented the date for starting contacts with the owners/property holders on 04/22/2024,
and in-person service on 05/07/2024;

Signing of the delivery term for the drainage works in Ponte do Gama;

Start of works at Campo do Rodoviário in Barra Longa.

Issuance of the Service Order to begin the reconstruction work at Campo do Rodoviário and the renovation of Quadra da Volta da Capela.
CIF's statement in response to the request of the Court of the 4th Court in relation to the process of cash payment for rural structures of AXIS 8.

Deliberation 756, of 02/21/2024, approved the closure of item “b” of clause 84.

Signing of the delivery agreement for the reconstruction work on the culvert in Barretos in the Municipality of Barra Longa.

Signing of the delivery term for the gabion containment works on the banks of the do Carmo River at LMG-829;

The judge granted the CIF, on 01/26/2024, an additional 20 days for claiming on the AXIS 8 hub;

In a meeting on 01/23/2024, the Judge requested the Renova Foundation return to the court by 02/06/2024 with a detailed proposal, containing revisions requested by the court in response to AXIS 4. New hearing scheduled for 03/07/2024.

Drainage works in Ponte do Gama completed;

The works on the Barretos Manhole have been completed;

Completion of containment works in gabion wall on the banks of the Carmo River (LMG-829);

Deliberation 741 of 12/14/2023, approved the closure of paragraphs “d", “e" and “l" of clause 84, according to the verification report by the independent auditor EY and NT CT-Infra nº 24/2023;

The activities of the new road maintenance contract began to replace the previous contract.

Start of mobilization of the road maintenance contract to replace the previous contract

Resolution 738 of 11/09/2023 approved the closure of paragraphs "c", "g" and "q" of clause 84 and clauses 86-caput and 87-caput of PG-10, according to the verification report by the independent auditor EY and NT CT-Infra nº 24/2023.

Start of the new civil maintenance contract replacing the previous contract

Maintenance on 42.19 km of unpaved roads

Start of works on the Barretos Manhole in Barra Longa

Start of gabion works on the right bank of the do Carmo River in Acaiaca

Inauguration of Ponte do Gama Public Assets (Field, Court and Arena) by the community;

Start of drainage works in Ponte do Gama;

Maintenance of paved roads – Final delivery – Section: Godinho x Macau x Bonsucesso;

Maintenance of paved roads – Final delivery – Section: Quindumba x Godinho Bridge – Samarco Antenna way;

Maintenance of 25.00 km of paved roads;
Maintenance of 65.23 km of unpaved roads.

Signature of the Term of Delivery of the Public Assets of Ponte do Gama

Delivery of furniture, printed projects and a manual for Public Facilities in Ponte do Gama

Maintenance on 81.10 km of unpaved roads;

- Track maintenance in Ponte do Gama, with running spout application;
- Painting and final finishing of the multi-sport court in Ponte do Gama;
- Completion of the installation of chinaware and metals in the Ponte do Gama changing room;
- Completion of the riding arena in Ponte do Gama;
- Completion of the access to the Cruise in Ponte do Gama;
- Meeting - Presentation of the mitigation plan in the Campo de Pedras project;
- Obtaining LAS-RAS from Campo de Pedras;
- Technical visit to new competition for track maintenance;
- Maintenance of 61.30 km of unpaved roads;
- Technical Visit for new competition for Civil Works.

Mariana:
- Signing of the term of delivery of works of the Bento Rodrigues bridge;
- Signing of the term of delivery of works on the Santa Rita bridge and walkway;
- Completion of the concreting of the court floor;
- Completion of 83% of the locker room;
- Completion of 82% of the arena;
- Installation of 88% of the grass in the field;
- Virtual technical visit - Campo de Pedras competitive process.

- Campo de Pedras - Precautionary inspections;
- Campo de Pedras - Opening of SR;
- Ponte do Gama public facilities - Planting grass on the soccer field
- Ponte do Gama public facilities - Concreting of 2 sections of the court floor"
"- Completion of works on the Bento Rodrigues bridge;
- Completion of works on the Santa Rita bridge and walkway;

Barra Longa

-Installation of stringers and pre-slabs, framing and concreting of the Bento Rodrigues Bridge slab.

Mariana

- Public Facilities Ponte do Gama - Completion of the concrete base of the SAA of Ponte do Gama;
- Public Facilities Ponte do Gama - Installation of a fence around the boundary of the land;
- Public Facilities Ponte do Gama - Completion of the main metallic structure of the court;
- Campo de Pedras - Payment of the 1st installment related to the purchase of the land.

Barra Longa

"Acaica

Opening of SR 547746043 for the process of contracting the service of: Construction of Gabion for containment on the left bank of the Carmo River."
"Barra Longa

- Signature of the Exhibition Park acceptance term;
- Event to hand over the Exhibition Park to the community, held on 11/12/22;
- Completion of the Campinas, Juca Ponciano, Tiara and Borba bridges;
- Signing of the acceptance term for the Bueno, Curvinas, Campinas and Juca Ponciano bridges;
- Opening of SR 547746043 for the process of contracting the service of: Construction of the João Tavares tailings landfill."

Mariana

"Mariana
- Recreation complex of the Ponte do Gama Community (soccer field, horseback riding arena and sports court) - Community visit to the work;
- Recreation Complex of the Ponte do Gama Community (soccer field, horseback riding arena and multi-sports court) - Installation of the 37.5kva Transformer that will supply the Association and the Public Assets of Ponte do Gama;
- Campo de Pedras - Presentation of the Football Field project to the Community of Pedras;
- Campo de Pedras - Signature of the land purchase and sale agreement;
- Completion of the Campinas Footbridge."

Activities Ponte do Gama:
- Launching and backfilling court foundations – completed activity;
- Concreting of the access ramp to the cruzeiro – activity concluded;
- Spreading the gravel ballast on the court;
- Spreading the coarse sand layer in the field;
- Settlement of masonry in the locker room;
- Confection of the reinforcements of the field wall.

Beginning of staking activities on the Bento Rodrigues Bridge.
Campo de Pedras - Payment of the formal sharing of the request for rectification of the rural area was made on 10/31 to proceed with the acquisition of the land.
Concreting of the decks of the Juca Ponciano Bridge.
Concreting of the decks of the Tiara Bridge.
Execution of the board and guardrail for the Campinas x Barretos suspension bridge.
Issuance of the AVCB of the Barra Longa Exhibition Park.
Maintenance on 27.6km of unpaved roads;
Resumption of activities on the Santa Rita bridge on 10/18/22 after release by IPHAN.
Staking and concreting of the crowning block on the Borba Bridge.

- Start of access maintenance activities by the new contractor;
- Maintenance of 19.8 km of unpaved roads;
- Conclusion of foundation pile activities on the Borba bridge;
- Start of cable laying activities on the Campinas walkway;
- Public Facilities Ponte do Gama - Assembly of formwork for the locker room pillars and formwork for the arena;
- Public Facilities Ponte do Gama - Execution of pedestrian access (Safety Walk);
- Slope protection, completion of bioengineering on all properties.

Community visit to the Ponte do Gama Public Facilities complex to monitor the works;
Completion of the mobilization of the new maintenance contractor for paved and unpaved roads;
Start of activities of the new civil works contract in the maintenance of “temporary housing” buildings;
Public Facilities Ponte do Gama - Completion of the treatment of field strips;
Completion of 01 property (D016) in the slope protection project for complex structures;
Interdiction of works on the bridge and footbridge of Santa Rita by archeology on 08/15/2022;
Completion of the work on the Manhole Curvinas e Bueno in Barra Longa.

- Kick-Off meeting of the contractor Terrayama regarding the scope of access maintenance;

- 13.70 km of maintenance of unpaved roads carried out;

- Beginning of the works on the Bueno Bridge in Barra Longa;

- Soccer field, sports court and Ponte do Gama horse riding arena:
• Completion of definitive vehicle access;
• Safety walk between contractors and SESMT inspection;
• Completion of the excavation of the locker room foundation;
• Stapled soil activities in progress. 30% completed;

- Slope Protection, Complex Structures - Completion of activities owned by D031;

- Slope Protection, Complex Structures - Completion of activities owned by D010;

Start of works on the Campinas walkway in the municipality of Mariana;

Maintenance of 69.97 km of unpaved roads in the municipalities of Mariana and Barra Longa;

Completion of 43.80 km of maintenance on paved roads in the municipalities of Mariana and Barra Longa;

Completion of the RIP RAP containment services, installation of a protective screen over the new jersey barrier, fencing, vertical signage of the new access, referring to the complementary works of the Exhibition Park in the municipality of Barra Longa;

Conclusion of the contracting process of the new Civil Works contract (Kick Off carried out on 06/20/22) for continuity of service to buildings;

Slope of Complex Rural Structures - Completion of 01 property in a total of 04 - PG-10;

Status of the works in the recreation complex for Ponte do Gama (Football Field, horseback riding arena and multi-sport court):
- 100% mobilization completed;
- 40% earthworks;
- start of drainage;

Public facilities Ponte do Gama - beginning of plant suppression;

Slope of Complexes - Start of field activities;

Slope of Complexes - conclusion of D035

Start of works on the Tiara and Curvinas bridges;

Maintenance of 46.50 km of unpaved roads;

Start of mobilization of the contractor to carry out the reconstruction of bridges;
Completion of the ETE at the Barra Longa Exhibition Park;
Protection of complex rural structure slopes - Kick-off held on 04/05/2022 with supplier Intech;
Ponte do Gama sports complex - Kick-off held on 04/19/22 with the supplier Degraus.

Mariana

Completion of 5 complex rural structures under the RBAR contract triggered on 01/17/22. 3 structures completed in March. *D63 civil structure completed, pending installation of drinking fountain.
SO request for installation of a hydraulic pump on property D014 - Complex Rural Structures;
Public Facilities Ponte do Gama - In the process of approval of the APRO by the Committee, with a kick-off expected in April/22.
Protection of complex rural structures slopes - Application approved. Handover held on 03/31/22 in Mariana;
Land negotiation for the acquisition of the land in the Pedras field in Mariana;

Barra Longa

Completion of the base and sub-base of the access to the Barra Longa Exhibition Park;
Completion of the application of HMA asphalt in the access work to the Barra Longa Exhibition Park;
Hold a kick-off meeting on 03/29/2022 with the contractor responsible for carrying out the reconstruction of the bridges in Mariana and Barra Longa;
Completion of the installation of the tanks in the ETE (Sewage Treatment Station) of the Barra Longa Exhibition Park;

Barra Longa

Suspension of activities in Barra Longa according to an official letter from the City Hall between 02/03 to 02/14/22

Completion of the landfill for the access to the Exhibition Park in Barra Longa.

Mariana

RBAR contract activated and mobilized to complete 05 structures. Mobilization Started on 01/17/2022
Ponte do Gama Public Facilities - In the APRO validation phase
Contracting process for complex rural structures concluded - APRO is being validated - PCT 1
Contracting process for complex rural structures in phase of commercial completion PCT 2
Protection of complex rural structures slopes - in the commercial analysis phase
Sharing Form withdrawn on 02/23/22 - The negotiation for the purchase and sale of the land is being analyzed by the Land Tenure team.

Barra Longa

High rate of rain in the first half of Jan/22 that impacted the activities in progress in the municipality of Barra Longa.

Completion of the assembly of the plates (scales) of the containment of the reinforced earth wall of the access to the Exhibition Park in Barra Longa.

Mariana

The RBAR contract was activated and mobilized to complete 05 structures. The mobilization started on 01/17/2022.
Ponte do Gama public facilities are in the commercial negotiation phase.
Contracting process for the execution of complex rural structures in the commercial completion phase PCT 1.
Contracting process for the execution of complex rural structures in the commercial completion phase PCT 2.
Protection of complex rural structure slopes - in the technical proposal review phase
Land negotiation phase/Formal withdrawal of sharing - Pedras Football Field

Completion of activities in the buildings of the Barra Longa Exhibition Park.
RBAR contract activated and mobilized to complete 07 structures. Expected start of works for January 2022.
Ponte do Gama Public Facilities is currently under commercial analysis.
Contracting process for the execution of complex rural structures in the commercial negotiation phase. Expected deadline for completion of the commercial rounds 01/28/2022.

Completion of activities in the locker room, horse stable and cattle sheds in the Barra Longa exhibition park;
Submitted for supplies Technical Opinion of the proposals received regarding the bidding for the reconstruction of the Mariana and Barra Longa bridges.

Construction of public facilities at Ponte do Gama - process under contract at Supplies.
Start of contracting and mobilizing a supplier for the construction of the soccer field for the sub-district of Pedras, awaiting the end of negotiation between the Land Tenure and the land owner.

Mariana

Current supplier showing low performance (RGL);
New hiring in progress to replace it;

Barra Longa

Draining the sand floor of the park's arena;
Start of base and sub-base activities for the park's internal paving;
Opening of SR for new contracting of civil works (Barra Longa and Mariana);
Technical visit with the proponents for the reconstruction of the bridges.

Completion of the assembly of the stage cover at the Exhibition Park;
Beginning of containment activities in armed land in the works of access to the Exhibition Park;
Start of the activities of the sewage network related to the ETE of the Exhibition Park.

Start of work on the access to the Exhibition Park;

Pre-assembly of the stage cover structure;

Completion of electrical maintenance at Manoel Lino Mol square;

Opening of the contracting process for rebuilding the bridges;

Signing of the Waste Transfer Stations works agreement in the Municipality of Barra Longa
Concreting of the stage slab at the Barra Longa exhibition park;
Completion of the contract for the execution of the Casa da Banda works;
Approval for complementary works in the exhibition park by the CRP-RBAR contract (Access and WWTP - Sewage Treatment Plant).

Developed and completed the projects for the bridges Bueno, Juca Ponciano, Tiara, Tomador de Agua, Borba, Ouro Fino (Novo Bento), Santa Rita and Passarela Campinas Barreto.
Resumption of activities with full staff: at the Exhibition Park,
street repair and paving, and maintenance of temporary housing in Barra Longa.

Completion of construction works of 12 complex structures.

Completion of works of all simple structures.

Designed and completed projects for the Bueno, Juca Ponciano, Tiara, Tomador de Agua, Ouro Fino (Novo Bento) and Santa Rita bridges and for the Campinas Barreto Bridge. Projects for the Curvinas and Borba Bridges are scheduled for 06/15/2021.

Works were suspended by PMBL through letter 55/2021 and 58/2021 received on 05/25/2021 and 05/27/2021 for a period of 10 days, given the outbreak of COVID-19 in the municipality and possible collapse of the health system. The FR requested that the guidelines provided in letter 55-2021-SEMSA be followed and that the staff remain in the locality, in view of the need to comply with quarantine in case of displacement.

Completion of the Waste Transfer Stations works in the Municipality of Barra Longa

Approved by DER-MG, the project for access to the Barra Longa Exhibition Center.

The Change Management process was initiated to adapt the current schedule to changes in the scope of the program and subsequent definition of a new baseline.

Meeting the claims for restoration in compensatory works and recovering historical, cultural and artistic memories in the municipality of Barra Longa.

The Change Management process was initiated to adapt the current schedule to changes in the scope of the program and subsequent definition of a new baseline.
Meeting the claims for restoration in compensatory works and recovering historical, cultural and artistic memories in the municipality of Barra Longa.

Completion of improved access road from the Borges Stream to the Dike in sector 4;
Execution of a temporary flow conduction system for the Borges stream

Delay in the release of the scope of the housing renovation project due to a case in Court.

Possible problems with residents regarding authorization to access the homes to carry out activities, due to COVID-19.

Loss of productivity due to mitigation and prophylactic measures due to COVID-19.

Publication by the Barra Longa Municipal Office of Decree 1,933 on 03/15/2021 instructing that starting 03/16/2021 all field activities are to be suspended. Third-party employees have been working remotely since 03/16/2021.

Publication by the Barra Longa Municipal Office of Decree No. 1.998/21, which determined new guidelines, including the release of activities performed by Renova's third parties, limiting the resumption of this active staff to 50% of the employees, all residents of Barra Longa. Activities resumed on 03/29/2021.

Covering potholes with hot mix asphalt (HMA) on the interchange MG 262 to Acaiaca.

Maintenance works on the Barra Longa Gesteira access road.

Maintenance works on the access to the Borba Bridge (Jair Possidoeno da Silva).

Maintenance works on the access road to the Barra Longa transfer station;

Road maintenance activities in the Barra Longa were temporarily halted due to
access/weather conditions.

Maintenance activities at the Chopoto Simplicio access (Dominiguitte);

Finalization of the activities on the Barra Longa access road; removal of earth and cleaning of the asphalt;

Electrical and hydraulic installations started in the main building, barn and warehouses.

Completion of masonry, roughcasting and plastering in the barns and warehouses of the Exhibition Center;

Beginning of the assembly of the metallic structures in the Main Building of the Exhibition Park.

Masonry activities started at the Main Building of the Exhibition Park.

10.95 km of municipal roads in Mariana, Barra Longa and Acaiaca received maintenance works.

Park

• Structure of Main Building - Floor 2;
• SPDA Underground;
• Stable structure;
• Conduits and Electrical Boxes;
• Wastewater System;
• Cold Water Network;
• Metallic coverings;
• Slab Main Building Level 385.00;
• Masonry of Warehouses;
• Roughcast and Plaster work.

Road Maintenance

Paving works completed in the following streets:

Primeiro de Janeiro;
Capitao Manoel Carneiro;
Monsignor Horta in the Barra Longa Municipality.

Carrying out paving works on Floriano Peixoto Street - in the Municipality Barra Longa;

Covering holes on the stretch between the Monsenhor
Horta Bridge and Monsenhor Horta (Secondary Road) with hot mix asphalt (HMA).

Resumed Gesteira water pipeline actions.
Maintenance works on 29.8 km of unpaved access roads
Started the actions to improve the Barra Longa garbage transfer area
Execution of repairs to return the property of Mr. Paulo Carlos Ribeiro
Continued the paving activities on Matias Barbosa Street in the Barra Longa Municipality
Concrete slab for main building of the Barra Longa Exhibition Center;
Completed Volta da Capela wastewater system.

There were no relevant events in October.

Completion of 74 Simple Support Structures: 23 Troughs, 01 Porter and 01 Water Station in Rio Doce/MG; 15 Troughs, 07 Water Stations and 08 Porters in Barra Longa/MG, 03 Troughs, 08 Porters in Mariana/MG, 05 Troughs and 01 Water Stations in Santa Cruz do Escalvado/MG, 02 Troughs and 03 Porters in Ponte Nova/MG.
Renova Foundation approved organizational charts for renovation, maintenance and reconstruction of buildings and renovation works for public goods.

Return of the works of the Exhibition Park, in Barra Longa / MG;
* Completion of 69 simple Support Structures: 30 troughs and 08 gates in Rio Doce / MG, 10 troughs , 02 water troughs and 02 gates in Barra Longa / MG, 03 troughs , 01 water trough 05 gates in Mariana / MG, 05 troughs and 01 water trough in Santa Cruz do Scalvado/ MG, 01 water trough and 01 gate in Ponte Nova / MG;
* Completion of the paving work of Camargos in Mariana / MG

• Field activities in Barra Longa/MG have been suspended since March 2020 due to the coronavirus pandemic.
• Resumption Plans for each front are under evaluation by the Renova Foundation.
• Reopening Plan for the Exhibition Park was approved by the Barra Longa/MG Municipal Office in July 2020.
• Works related to PASEA (Socioeconomic and Environmental Adequacy Plan for Rural Properties) have been approved by the Municipal Office of Barra Longa/MG to resume in July 2020.

• Field activities in Barra Longa (MG) have been suspended since March 2020 due to the Coronavirus pandemic.
• Plans to resume each front are under evaluation by the Renova Foundation.
• The Municipality of Mariana (MG) approved the resumption of the works related to PASEA (Socioeconomic and Environmental Adequacy Plan for Rural Properties) in June 2020.

• Field activities have been halted since March 20, due to the coronavirus pandemic.
• Plans to resume each front's activities were presented and are under evaluation by the Renova Foundation.
• Fronts cleared to resume activities: Restoration of the "Casa da Banda de Monsenhor Horta" and repairs to the Camargos sidewalks, both in Mariana, Minas Gerais.
• The Renova Foundation authorized the resumption of construction work related to PASEA (Plan for the Socioeconomic and Environmental Adapting of Rural Properties), which are now awaiting authorization from the Municipalities of Mariana and Barra Longa, Minas Gerais, to resume activities.

• Field activities have been suspended since March 2020 due to the coronavirus pandemic.
• Plans for the resumption of each front were presented and are under evaluation by the Renova Foundation.
• Fronts already allowed to execute their activities: Restoration of the "Casa da Banda de Monsenhor Horta" and repairs to the Camargos sidewalks, both in Mariana/MG.

• Installation of a trough and cattle guard in Mariana/MG and Barra Longa/MG, respectively.
• Renovation of the façade of a house in Barra Longa/MG.
• Installation of a screen for maintenance works of a building in Barra Longa/MG.

• Installation of a drinking fountain, two troughs and three gates in Barra Longa/MG.
• Maintenance of paved access roads in the following sections: Paracatu x Aguas Claras and Camargos.
• Maintenance of unpaved access roads in the following sections: PCH de Bicas x Saint Gobain, Camargos x Mina Del Rey, Ponte do Bucao x Aguas Claras, dirt road between Paracatu and Pedras, Campinas x Gesteira, among others.

• Installation of three drinking fountains in Barra Longa/MG and Santa Cruz do Escalvado/MG.
• Performed maintenance of paved access roads in the following sections: Dominguitis x Chopoto, Florestina and Access Road to Maria Auxiliadora.
• Maintenance of unpaved access roads in the following sections: Vargem Alegre Farm, Barretos Access Road, Quebra Chifre Ranch, Monsenhor Horta x Paracatu de Cima, Paracatu x Bucao Bridge, Camargos x Mina del Rey, Paracatu Church, Paracatu Margem Direita, Bicas Plant, Mina del Rey x Bicas PCH Plant, Cachaça Tiara Stream Crossing, Morro da Mandioca, Favas Ranch, Paracatu Ranch, among others.
• Due to demonstrations, activities in the town of Barra Longa/MG were halted in the period from 11/12/2019 to 01/26/2020, directly impacting the program deliveries.

• The reconstruction of support structures for rural properties (complex), scheduled for 2019, has not been started.
• Cause: Change of scope and contracting strategy. Countermeasures: Define scope of action and contract company for execution (Completed).
• The reconstruction of the Barra Longa and Mariana bridges, scheduled for 2019, has not been started. Causes: Delay in the contracting process for execution, pending engineering issues and delay in issuance of environmental licenses. Countermeasures: Obtain signature for the contract addendum, review the engineering projects and obtain final approval by the Technical Board of Tailings to start the works (Complete).
• The reconstruction of the Barra Longa exhibition park, scheduled for 2019, has not been started. Causes: Indetermination by the Municipal Office of the location of the exhibition park, delay in the contracting process and pending engineering issues. Countermeasures: Perform integrated planning for the works in the surroundings of the exhibition park (nearby park, access roads and houses).
• The reconstruction of the soccer fields in the municipalities of Mariana and Barra Longa (Municipal Field of Barra Longa, Pedras and Ponte do Gama), scheduled for 2019, has not been completed. Causes: Delay in the contracting process for execution, pending engineering issues (Campo Municipal), indetermination of the reconstruction site (Pedras) and delay in the acquisition of land for reconstruction (Ponte do Gama). Countermeasures: Validate the project of the field with the Community and Public Authorities (Campo Municipal), define a location for the reconstruction of the field (Pedras) and obtain the signature of the land acquisition contract (Ponte do Gama).
• Completion of the Barralonguense soccer field.
• Completion of reconstructed buildings in Mariana and Barra Longa.
• Deliveries of the following works: 04 renovated buildings, 03 renovated public goods, 02 reconstructed buildings, 60 building maintenance works, 02 recovered access roads, 290 access road maintenance works, 55 reconstructed support structures, 01 reconstructed soccer field, 01 reconstructed bridge and 01 renovated yard.

• Maintenance of two buildings in Mariana.
• Installation of seven gates in Mariana and Barra Longa.
• Maintenance of unpaved access roads in the following sections: Bom Sucesso x Felipe dos Santos x Interchange BR 262, Mariana x Bento Velho, Ponte Nova x Bom Sucesso x Barra Longa, alternative access roads in Camargos, Camargos x Mina del Rey, Bento Velho x Camargos and access road in Barretos.
• Installation of horizontal signage on roads in Acaiaca and Barra Longa.
• Power grid repair in Mariana.

• Maintenance of two buildings in Mariana.
• Installation of seven gates in Mariana and Barra Longa.
• Maintenance of unpaved access roads in the following sections: Bom Sucesso x Felipe dos Santos x Interchange BR 262, Mariana x Bento Velho, Ponte Nova x Bom Sucesso x Barra Longa, alternative access roads in Camargos, Camargos x Mina del Rey, Bento Velho x Camargos and access road in Barretos.
• Installation of horizontal signage on roads in Acaiaca and Barra Longa.
• Power grid repair in Mariana.

• Renovation of a building (C.S.).
• Maintenance of three buildings (Bento Rodrigues School, M.A.M. and Water Pumping Station - Gesteira).
• Maintenance of Unpaved Access Roads: Stretch Vila Samarco x Bento Velho and Stretch Curvina Bridge x Rocinha x Gesteira.
• Reconstruction of support structures: installation of three gates (F.H.C. and G.A.C.) and a drinking fountain (J.R.C.).
• Power grid repair works (J.R.).

• Maintenance of two buildings (Sao Jose Parish and Paracatu School).
• Maintenance of Unpaved Access Roads: Tributary Stretch 11, Bonito x Agua Fria Stretch, Rocinha Stretch, access to properties (R.F.S., H.F.B. and Quiteria Farm) and access to the Barra Longa Exhibition Park.
• Reconstruction of support structures: installation of three gates (J.M.C., M.B.C., W.M.S.), a barn (S.C.A.) and a chicken coop (A.T.N.).
• Installation of road signs: Gesteira road (lane narrowing).
• Implementation of riprap (C.S.).

• Renovation of building (A.S.V.).
• Maintenance of buildings (G.J.F., J.V.M. and Z.M.C.).
• Maintenance of Paved Access Roads: Raimundo Xavier Alves Street, Pedro Jose Pimenta Avenue (two interventions), Venancio Lino Mol Street, Edmundo Costa Lana Avenue, Getulio Etrusco Street and Matias Barbosa Street.
• Maintenance of Unpaved Access Roads: Morro da Cassava stretch, Borba stretch, stretch between Paracatu and Ponte do Bucao, Pedras stretch (Left Bank) and Usina Road (Bicas x Ponte do Gama).
• A meeting was held with the Technical Board on 11/22/18 in the state capital to talk about the repair of damaged infrastructure (207 addresses) located in Barra Longa. AEDAS failed to attend. PG10 presented its recovery plan for the houses and it was decided that the infrastructure area will start the visits to the residences that the program defined as at risk. Two hundred houses have been visited.

• Completion of the Access Road Recovery activities (PF0039) - Morro do Petisco (Facao Access) and 1º de Janeiro Street in Barra Longa.
• Bridge Reconstruction: Signing of the bridge reconstruction contract in the towns of Mariana and Barra Longa;
• Renovation of a building (A.M.T).
• Building Maintenance: H.F.T. and G.S.C.
• Maintenance of Unpaved Access Roads: Barretos/Pedras stretch, Gesteira/Campinas stretch, Area B stretch (Paracatu de Baixo - Left Bank), Pedras/Furquim stretch and Access Road J.A.A Property.
• Maintenance of Paved Access Roads: Access property A.B., Highway Ramp Marginal Sul (Acaiaca), Highway Ramp (Monsignor Horta), Padre Esperidiao Street (Acaiaca) and Stretch Jose Bonifacio Street / Sao Goncalo Street (Acaiaca);
• A meeting was held on 11/22/18 in the State Capital with the TB on the repair of damaged infrastructure (207 addresses) located in Barra Longa. AEDAS failed to attend. At the occasion, PG-010 presented its recovery plan for the dwellings and it was defined that the Infrastructure Team will initiate the visits to the residences defined as at risk. 200 houses have been visited so far.

• Building Maintenance: A.T.N., Papa Galinhas Site, M.E., C.J.G., Capina dos Quintais - surroundings of Barra Longa Exhibition Center.
• Maintenance of Unpaved Access Roads: Stretch Mina del Rei / Camargo, Stretch Claudio Manuel / Dobla, Stretch Quindumba Bridge / Onça Bridge, Stretch Asa Branca Farm / PCH de Bicas, Acess road Cafurna Site, Stretch Barreto Stream, Stretch Camargos / Bento Velho, Access road Moinho Site, Stretch Povoado de Tanque, Stretch Vila Samarco / Interchange Bento Rodrigues, and Stretch Barreto / Moinho Site.
• Support structures: signing of the contract to rebuild simple structures.
• A meeting was held with the TB on 11/22/18, in the state capital, to talk about the repair of damaged infrastructure (203 addresses) located in Barra Longa, which AEDAS did not attend. PG010 presented its recovery plan for the houses and it was decided that the infrastructure area will start visiting the residences that the program defined as at risk. 171 houses have been visited so far.

• Support Structures: W.P., G.P., T.J., H.Z. and M.A.
• Building Maintenance: F.A.P.T. and Z.M.C.
• Renovation of Buildings: Shackle Factory.
• Maintenance of Unpaved Access Roads: Stretch Gesteira/Campinas, MG 362 Stretch Direction Nova Bridge, Stretch Curvina Bridge / Gesteira Bridge, Access road Curvinas / Joao Tavares, Access road Apaga Fogo Farm / Paiol do Cunha, Stretch Gesteira/Tabuoes, Stretch Fonseca / Serra da Luzia Access road Paracatu de Baixo / Campinas and Stretch Alvinopolis/Fonseca.
• Maintenance of Paved Access Roads: Coronel Olímpio Soares Pena Street (Alvinopolis).

• Support Structures: J.C.F. and N.H.P.
• Building Maintenance: Asa Branca Farm, M.A.G.
• Maintenance of Unpaved Access Roads: N.H.P., Section Paracatu x Pedras, N.R.G.P., J.L.C., C.A.X.
• Maintenance of Paved Access Roads: M.E.F.M., Municipal Office of Mariana - Section Fonseca / Santa Street -, Municipal Office of Alvinopolis - Sections 326 Antonio Basilio da Costa Street and Fonseca MG x Efigenia Street.
• Renovation of Buildings: M.L.V., M.B.D.A.
• A meeting was held with the TB on 11/22/18 on the repair of damaged infrastructure (203 addresses) located in Barra Longa. AEDAS failed to attend. At the occasion, PG-010 presented its recovery plan for the dwellings and it was defined that the Infrastructure Team will initiate the visits to the residences defined as at risk. 115 houses have been visited so far.
• On 04/29/19, the Status of Programs report was sent to the CIF, pursuant to item 1 of Resolution 267.

Deliveries of Support Structures, Renovation of Buildings, Reservoir Facilities, Tailings Transshipment Area, Urban Road Pavement, Maintenance of Unpaved Access Roads.

Deliveries of support structures, remodeling of buildings, reservoir facilities, waste transshipment area, paving of urban roads, maintenance of unpaved accesses.

Completed works include: support structures, renovation of buildings, maintenance of buildings, repairs to bridges and maintenance of unpaved access roads.

Reconstruction of five houses in Mariana.

Delivery of support structures, renovations of buildings, maintenance of buildings, repairs to bridges, installation of reservoir, electrical installation, demolition, yards, filling of potholes in the section of Trevo BR-262 up to the bridge Monsenhor Horta and maintenance of unpaved access roads.

Completed works include: drainage, support structures, renovation of buildings, maintenance of buildings, repairs to bridges, renovations at WWTP, installation of reservoir, filling potholes on the access roads to Monsignor Horta and maintenance of unpaved access roads.

Execution of renovation works, maintenance and reconstruction of houses, support structures (cattle grids, gates, storerooms etc.) and maintenance to roads.

The reconstruction of Mr. Marcio de Souza’s house has been completed. Contracting of the company that will fill potholes in paved roads - in Monsenhor Horta.
Delivery of the Municipal School Paracatu de Baixo, in Mariana.

The points Mariana X Bento and Camargos X Bento were delivered.
Presentation of the two projects to the Municipal Government (current and new location) to define the location of the Exhibition Park.

The scope of the Program was increased by 185 items, which led to an increase in the budget of the program by R$ 109 million and the deadline increased with 14 months. The justifications for this adjustment in the deadline were sent to the Technical Board on June 5.

The Program’s scope increased by 185 items, which resulted in an increased budget forecast and execution term.

The teams continued to work on renovating buildings, yards, support structures and bridges. Works on the Bicas bridge were completed on May 17.

The process of contracting companies to carry out civil works and other building reconstruction works has also been finalized.

Based on the assessment results, the Program’s scope was increased with the inclusion of 183 items. As a result, the deadline for the execution of the works was extended with 14 months.

The teams continued the renovations of buildings, yards, support structures, in addition to the bridges of Bicas and the ones between Mariana and Bento. The maintenance activities on access roads in Barra Longa and Acaiaca and the soccer field of Barra Longa also continued.

The processes for hiring the company that will carry out the construction of the rural structures in the areas affected by the dam collapse were finalized.

Renovation work on buildings, backyards, support structures, the Mariana-Bento and Bicas bridges, maintenance of access roads in Barra Longa and Acaiaca in Minas Gerais, and the Barra Longa football field are underway.

In February, meetings were held with companies that will perform the engineering services for the restoration and maintenance of unpaved roads.

In Mariana (MG), maintenance work was done on three stretches of unpaved access roads between Ponte do Gama and Fonseca. In the municipality of Barra Longa (MG), renovation on 13 backyards and lots was concluded. Furthermore, Green Gramados was hired for the application of grass on the Barralonguense and Rodoviarios soccer fields.

The renovation of an air monitoring station in Paracatu de Baixo, district of Mariana (MG), was delivered. Also completed were the renovations of 12 backyards and lots, besides the completion of the works to lift the rodoviarios field in Barra Longa (MG).

The projects of the Camargos-Bento Rodrigues and Bicas bridges were completed. The renovation of the Technical Reserve, located in Mariana (MG), was also completed. In November, activities started for the design of the project and the interconnection with the Cemig network of the houses under reconstruction.
In Alvinopolis (MG), the urban road was paved and the paved roads in the district of Fonseca were renovated. In Santa Rita Durao, district of Mariana, paved roads were also renovated in November.
In the municipality of Barra Longa (MG), 18 yards were renovated and the adjustments to the location that serves as bus station, classified as a public good, were completed.

In Mariana, work has begun on the reconstruction of the Mariana-Bento Rodrigues bridge and four rural properties. In addition, the projects of the Camargos-Bento Rodrigues and Bicas bridges are being developed. In the districts of Santa Rita Durao and Fonseca, paved roads were recovered, and, in Bento Rodrigues, the community garden was reopened.

In Barra Longa, the construction works on the José de Vasconcelos Lanna Municipal School were completed, as well as the renovation of three backyards and the cultural center Casa de Cultura. The site where the Coach station is located was lifted and the boarding area was adjusted.

Initiation of the setup of the construction sites for the renovation and reconstruction works of the bridges Camargo/Bento, Bicas and Real.

The renovation of and adjustments to the Jose de Vasconcelos Lanna Municipal School, in Barra Longa (MG), is still underway.

The company that will perform the maintenance of the paved roads used by Renova during the implementation of its programs in Territory 1 was selected.

In Barra Longa (MG), the renovation of the Exhibition Center was completed. The landfill was finished by using the tailings and by throwing a layer of sand on the area; Reno Mattress is being placed for surface protection, as well as the assembly of the construction site for the reconstruction of the houses of the village. In addition, the development of the detailed engineering of the bridges Camargo/Bento, Bicas and Real, in the Mariana (MG) region, is underway.

Completion of contracting processes for rebuilding and restoration of houses, rehabilitation of paved and unpaved roads, reconstruction of bridges and rehabilitation of support structures. Beginning of the recovery works on the backyards in Barra Longa (MG) and the reconstruction of the residences in Mariana (MG).

Completion of the reconstruction of houses in Raimundo Alves Xavier street, Barra Longa, Minas Gerais.

The contracts with the companies that were working on these fronts were finalized and new contracts are already under way, which justifies the temporary reduction of the recovery works and infrastructure.

The reconstruction of houses, cattle guards and fences in Barra Longa (MG) is in progress.

In Barra Longa (MG), there were technical visits for the restructuring of gardens and plots and the opening of the process and/or monitoring of the processes/projects: cracks (building renovation and maintenance), recovery of paved and unpaved roads, indoor cleaning of the municipality, garbage collection, restoration of the Xavier Hotel, land surveying, renovation and reconstruction of constructions and expert reports. Also, continuing in progress in the municipality are the process of recovery of non-paved roads, the activities related to lifting the roads and the reform and reconstruction of damaged buildings.

Whereas in Mariana (MG), the reform works to the cemetery of the Paracatu de Baixo district were completed, as well as three cattle guards and the fencing of a property, in addition to the survey of a house and land leveling of three houses and two locations where new housing will be built. There also was a mitigating renovation of the bridge connecting Mariana to Bento Rodrigues and the maintenance to unpaved roads is ongoing.

The definition phase for the program between Fundão and Candonga was approved.

Yards were delivered in Barra Longa (MG), a house was finished in Morro Vermelho and access roads were restored for the community. Whereas in Mariana (MG), the renovation of the Morro de Santana school and the cemetery wall were completed, as well as the conceptual engineering of two houses. Also, carried out were the maintenance on unpaved roads, the topography of 10 houses to be rebuilt, the expansion of the storage building for Sacred Arts and the renovation of the roof of the Mainart Farm and the installation of a tank.

In Barra Longa (MG), houses, cattle pens and yards were renovated and delivered to their owners, and access roads of the community were restored. In Mariana (MG), a topographic survey was done in 6 houses, which are to be rebuilt in the first construction phase, in addition to the delivery of 3 pens, 1 in Ponte do Gama and 2 in Paracatu de Cima, and the installation of a fence in Pedras. In Gesteira, removal of tailings took place.

In Barra Longa (MG) the recovery of the Barralonguense field was completed, as well as cattle pens and yards. So far, 96 houses and 34 shops were renovated in the same municipality. Whereas in Mariana (MG), a number of renovation actions are in progress, among which the renovation of the roof of the health center (UBS), the drilling for building the first three houses, the floor installation at the community center and the Chapel of Ponte de Gama, and the reconstruction of cattle grids between Paracatu de Cima and Ponte do Gama. Regarding the affected infrastructure, so far seven bridges have been rebuilt and 110 kilometers (68 miles) of unpaved roads have been recovered.

Several restoration works are in progress in Mariana (MG) and Barra Longa (MG), this month focusing on the reconstruction of a house and the renovation of another house and a store in Barra Longa. The continuous maintenance of the dirt road that connects Barra Longa with Ponte Nova was formalized with the Department of Roads (DER).

In Barra Longa, the renovation of two houses and a shop were completed and on October 30, the Manoel Lino Mol Square and the Beira Rio Promenade were opened to the public. With the completion of the restoration works the location was transformed into a multifunctional space, with elements that allow it to be used for social meetings, leisure, physical activities and sport, fostering the integration of the local population and a suitable destination of the public space.

In Mariana the Reconstruction Committee was formed to define the guidelines together with the socio-institutional team and other disciplines about the reconstruction of properties and rural structures. In Barra Longa and Gesteira, the renovation of three houses has been completed and the construction work on the Beira Rio Square and Avenue are in progress, as well as the renovation work to rural properties and riprap. Furthermore, the recovery of the pavement in Claudio Manuel has been completed as well as the 55 kilometers long asphalted roads in the region from Mariana to Barra Longa.